Terms of Service

Agreement to Terms

By accessing our website or using the services of Roof Repair Services LLC ("Company," "we," "our," or "us"), you agree to be bound by these Terms of Service. If you do not agree to these terms, please do not use our website or services.

Services Provided

Roof Repair Services LLC provides residential and commercial roofing services in the Greater Houston area, including but not limited to:

• Roof replacement and installation
• Storm damage repair and restoration
• Roof inspections and assessments
• Insurance claim assistance
• Emergency roof repairs
• Preventive maintenance

Estimates and Quotes

All estimates and quotes provided are based on our professional assessment at the time of inspection. Estimates are valid for 30 days unless otherwise specified. Final pricing may vary based on:

• Discovery of hidden damage during the project
• Changes in material costs
• Customer-requested modifications
• Code compliance requirements

Any changes to the original scope will be communicated and approved before proceeding.

Payment Terms

Payment terms will be outlined in your service agreement. Typically:

• A deposit may be required before work begins
• Progress payments may be required for larger projects
• Final payment is due upon project completion
• For insurance claims, we work directly with your insurance company when applicable

We accept various payment methods including checks, credit cards, and financing options where available.

Warranties

Roofing work performed by Roof Repair Services LLC is backed by:

• Workmanship Warranty: We stand behind our installation quality
• Manufacturer Warranties: Materials come with manufacturer warranties as specified
• GAF Warranty Programs: As a GAF Master Elite contractor, we offer enhanced warranty options

Specific warranty terms will be provided in writing with your service agreement. Warranties may be voided by improper maintenance, unauthorized repairs, or acts of nature.

Insurance Claims

When assisting with insurance claims:

• We provide documentation and estimates to support your claim
• Final approval and payment amounts are determined by your insurance company
• We are not responsible for claim denials or coverage disputes
• You remain responsible for deductibles and any costs not covered by insurance

Customer Responsibilities

As a customer, you agree to:

• Provide accurate information about your property and project needs
• Grant reasonable access to your property for inspections and work
• Remove or protect personal items near the work area
• Inform us of any known hazards or special conditions
• Make timely payments as agreed
• Communicate any concerns promptly

Scheduling and Delays

We strive to complete projects on schedule. However, delays may occur due to:

• Inclement weather conditions
• Material availability
• Permit processing times
• Discovery of additional work needed
• Circumstances beyond our control

We will communicate any significant delays and work to minimize inconvenience.

Limitation of Liability

To the maximum extent permitted by law, Roof Repair Services LLC shall not be liable for:

• Indirect, incidental, or consequential damages
• Damage caused by acts of nature after project completion
• Pre-existing conditions not visible during inspection
• Delays beyond our reasonable control

Our total liability shall not exceed the amount paid for the specific service in question.

Website Use

When using our website, you agree not to:

• Submit false or misleading information
• Interfere with website functionality
• Attempt unauthorized access to our systems
• Use automated tools to scrape content
• Violate any applicable laws

Intellectual Property

All content on our website, including text, images, logos, and designs, is the property of Roof Repair Services LLC and is protected by copyright and trademark laws. You may not reproduce, distribute, or use our content without written permission.

Dispute Resolution

Any disputes arising from these terms or our services shall be resolved through good-faith negotiation. If a resolution cannot be reached, disputes shall be handled in accordance with Texas law in the courts of Fort Bend County, Texas.

Changes to Terms

We reserve the right to modify these Terms of Service at any time. Changes will be effective when posted on this page. Your continued use of our website or services constitutes acceptance of the updated terms.

Severability

If any provision of these terms is found to be unenforceable, the remaining provisions shall continue in full force and effect.

Contact Us

If you have questions about these Terms of Service, please contact us: